GCC Clause Reference

Special Conditions

The Employer is ____________________

The Engineer is ____________________

The name and procurement reference number of the Contract is ______________________________________________________.

The Works consist of _____________________________________.

The Site is located at __________ and is defined in Drawings Nos.: _______________.

The Start Date shall be __________.

The Intended Completion Date for the whole of the Works shall be __________.

GCC 2.3

The following documents also form part of the Contract: ____________________________________________________________

GCC 4.1

The Employer’s specific approval is required for:

GCC 8.1

The Schedule of Other Contractors __________ part of the Contract

GCC 9.1

The Schedule of Key Personnel __________ part of the Contract

GCC 11.1

The Employer’s risks are as specified in the GCC.

GCC 13.1

The minimum insurance cover and deductibles shall be:

(c) The minimum cover for insurance of Equipment is __________.

(e) The minimum cover for insurance of property is __________

(f) The maximum deductible for insurance of property is _________

(g) The minimum cover for personal injury or death insurance is __________ with no deductible.

GCC 14.1

Site Investigation Report(s) __________ part of the contract.

GCC 25.2

Fees and types of reimbursable expenses to be paid to the Adjudicator are: __________.

GCC 25.3

The institution whose arbitration procedures shall be used is: __________.

Arbitration shall take place at: _______________

GCC 26.1

The Appointing Authority for the Adjudicator is: _______________.

GCC 27.1

The Contractor shall submit a revised Program for the Works within __________ days of delivery of the Notice of Acceptance.

GCC 27.3

The period between Program updates is __________ days.

The amount to be withheld for late submission of an updated Program is __________.

GCC 35.1

The Defects Liability Period is __________ days.

GCC 37.1

This Contract is a _______________ Contract.

GCC 44.1(l)

The following events shall also be Compensation Events:

GCC 45.1

The Engineer shall not adjust the Contract Price if taxes, duties and other levies are changed that subsequently affect the Contract Price.

GCC 47.1

The Contract __________ subject to price adjustment in accordance with Clause 47 of the Conditions of Contract.

GCC 48.1

The proportion of payments retained is __________ percent.

GCC 49.1

The liquidated damages for the whole of the Works are __________ of the final Contract Price per day.

The maximum amount of liquidated damages for the whole of the Works is __________ percent of the final Contract Price.

GCC 50.1

The Bonus for the whole of the Works is __________ percent of final Contract Price per day. The maximum amount of Bonus for the whole of the Works is __________ percent of the final Contract Price.

GCC 51.1

The Advance Payment will be equivalent to __________ percent of the Contract Price and will be paid in Ethiopian Birr. It will be paid to the Contractor no later than __________.

GCC 51.3

The Advance Payment will be repaid by deducting proportionate amounts from each payment certificate during the period starting __________ months after the Start Date and ending __________ months after the Start Date.

GCC 52.1

The Contract Security shall be for __________ of the Contract Price:

GCC 58.1

The date by which operating and maintenance manuals are required is __________.

The date by which "as built" drawings are required is __________.

GCC 58.2

The amount to be withheld for failing to produce "as built" drawings and/or operating and maintenance manuals by the date required is __________ Ethiopian Birr.

GCC 60.1

The percentage to apply to the value of the work not completed, representing the Employer’s additional cost for completing the Works, is __________.